republic-os/legal/us/code/title-16/chapter-12/section-806.md

type, title, description, jurisdiction, corpus, kind, title_number, title_name, chapter_number, chapter_name, section, citation, status, release_point, release_date, source, source_url, source_identifier, source_file, source_hash, raw_snapshot_hash, text_hash, retrieved_at, confidence, tags

type	title	description	jurisdiction	corpus	kind	title_number	title_name	chapter_number	chapter_name	section	citation	status	release_point	release_date	source	source_url	source_identifier	source_file	source_hash	raw_snapshot_hash	text_hash	retrieved_at	confidence	tags
LegalText	16 U.S.C. § 806	Time limit for construction of project works; extension of time; termination or revocation of licenses for delay	us	united_states_code	code_section	16	CONSERVATION	12	FEDERAL REGULATION AND DEVELOPMENT OF POWER	806	16 U.S.C. § 806	current	119-100	2026-06-26	official	https://uscode.house.gov/download/releasepoints/us/pl/119/100/xml_usc16@119-100.zip	/us/usc/t16/s806	data/legal/raw/us/code/title-16/usc16.xml	84e63e781ace34348cc98eed65d58966e29140fad3a10ae3ed0030e8eb7b3c58	7be8950da5a93cac7c98e4576ce00340f2aba5e8e46d29915382c203c421d503	6b645962b948b72deed8bb94dc0be6a7af6883230b8814f8397001eb94e32fb5	2026-07-04	official	legal us-code

16 U.S.C. § 806 - Time limit for construction of project works; extension of time; termination or revocation of licenses for delay

Text

The licensee shall commence the construction of the project works within the time fixed in the license, which shall not be more than two years from the date thereof, shall thereafter in good faith and with due diligence prosecute such construction, and shall within the time fixed in the license complete and put into operation such part of the ultimate development as the commission shall deem necessary to supply the reasonable needs of the then available market, and shall from time to time thereafter construct such portion of the balance of such development as the commission may direct, so as to supply adequately the reasonable market demands until such development shall have been completed. The periods for the commencement of construction may be extended for not more than 8 additional years, and the period for the completion of construction carried on in good faith and with reasonable diligence may be extended by the commission when not incompatible with the public interests. In case the licensee shall not commence actual construction of the project works, or of any specified part thereof, within the time prescribed in the license or as extended by the commission, then, after due notice given, the license shall, as to such project works or part thereof, be terminated upon written order of the commission. In case the construction of the project works, or of any specified part thereof, has been begun but not completed within the time prescribed in the license, or as extended by the commission, then the Attorney General, upon the request of the commission, shall institute proceedings in equity in the district court of the United States for the district in which any part of the project is situated for the revocation of said license, the sale of the works constructed, and such other equitable relief as the case may demand, as provided for in section 820 of this title.

(June 10, 1920, ch. 285, pt. I, § 13, 41 Stat. 1071; renumbered pt. I, Aug. 26, 1935, ch. 687, title II, § 212, 49 Stat. 847; amended Pub. L. 115–270, title III, § 3001(b), Oct. 23, 2018, 132 Stat. 3862.)

Notes

Editorial Notes

References in TextProceedings in equity, referred to in text, were abolished by the adoption of rule 2 of the Federal Rules of Civil Procedure, set out in the Appendix to Title 28, Judiciary and Judicial Procedure, which provided that “there shall be one form of action to be known as ‘civil action’ ”.

Amendments2018—Pub. L. 115–270 substituted “for not more than 8 additional years,” for “once but not longer than two additional years” in second sentence.

Statutory Notes and Related Subsidiaries

Extension of Time To Commence Construction of Certain Hydropower ProjectsPub. L. 119–90, May 11, 2026, 140 Stat. 820, provided that: “SECTION 1. EXTENSION OF TIME TO COMMENCE CONSTRUCTION OF CERTAIN HYDROPOWER PROJECTS.“(a) Definition of Covered Project.—In this section, the term ‘covered project’ means a hydropower project with respect to which the Federal Energy Regulatory Commission issued a license before March 13, 2020. “(b) Authorization of Extension.—Notwithstanding section 13 of the Federal Power Act (16 U.S.C. 806), on the request of a licensee of a covered project, the Federal Energy Regulatory Commission may, after reasonable notice and for good cause shown, extend in accordance with subsection (c) the period during which the licensee is required to commence construction of the covered project for not more than an additional 6 years beyond the 8 years authorized by that section. “(c) Period of Extension.—An extension of time to commence construction of a covered project under subsection (b) shall—“(1) consist of not more than 3 consecutive 2-year periods; “(2) begin on the date on which the final extension of the period for commencement of construction granted to the licensee under section 13 of the Federal Power Act (16 U.S.C. 806) expires; and “(3) end on the date that is not more than 6 years after the latest date to which the Federal Energy Regulatory Commission is authorized to extend the period for commencement of construction under that section. “(d) Reinstatement of Expired License.—If the time period required under section 13 of the Federal Power Act (16 U.S.C. 806) to commence construction of a covered project expires after December 31, 2023, and before the date of enactment of this Act [May 11, 2026]—“(1) the Federal Energy Regulatory Commission may reinstate the license for the applicable project effective as of the date of expiration of the license; and “(2) the extension authorized under subsection (b) shall take effect on the date of that expiration.”